48 CFR 832.111-70 - 832.111-70 VA contract clauses for non-commercial purchases.

Regulations last checked for updates: May 16, 2024

Title 48 - Federal Acquisition Regulations System last revised: May 14, 2024

View all text of Subpart 832.1 [832.111 - 832.111-70]

832.111-70 - 832.111-70 VA contract clauses for non-commercial purchases.

(a)(1) Insert the clause at 852.232-70, Payments Under Fixed-Price Construction Contracts (Without NAS-CPM) in solicitations and contracts that contain the FAR clause at 52.232-5, Payments Under Fixed-Price Construction Contracts, and if the solicitation or contract does not require use of the “Network Analysis System—Critical Path Method (NAS-CPM).”

(2) If the solicitation or contract includes guarantee period services, the contracting officer shall use the clause with its Alternate I.

(b)(1) Insert the clause at 852.232-71, Payments Under Fixed-Price Construction Contracts (Including NAS-CPM), in solicitations and contracts that contain the FAR clause at 52.232-5, Payments Under Fixed-Price Construction Contracts, and if the solicitation or contract requires use of the “Network Analysis System—Critical Path Method (NAS-CPM).”

(2) If the solicitation or contract includes guarantee period services, the contracting officer shall use the clause with its Alternate I.

[83 FR 49306, Oct. 1, 2018]

authority: 40 U.S.C. 121(c); 41 U.S.C. 1303; 41 U.S.C. 1702; and 48 CFR 1.301 through 1.304

source: 73 FR 2717, Jan. 15, 2008, unless otherwise noted.

cite as: 48 CFR 832.111-70